Terms & Conditions
Effective Date: 30-March-2025
Last Updated: 30-March-2025
Welcome to Wooden Deco!
These Terms and Conditions outline the rules and regulations for using our website and services. By accessing this website, you agree to comply with these terms. If you do not agree, please do not use our services.
1. General Information
1.1. Wooden Deco specializes in custom woodwork, including kitchens, doors, furniture, and other home decor solutions.
1.2. Our services include consultation, design, production, and installation of wooden products.
1.3. These terms govern the use of our website and any transactions made through it.
2. Orders & Payments
2.1. Orders for custom woodwork require a deposit before production begins.
2.2. Full payment must be made before delivery or installation unless otherwise agreed.
2.3. Prices are subject to change based on material costs and project specifications.
2.4. We accept payments via [list payment methods, e.g., bank transfer, credit card, etc.].
3. Custom Orders & Production
3.1. Custom orders are crafted based on the specifications agreed upon with the client.
3.2. Production timelines vary depending on the complexity of the project. Estimated completion dates will be provided.
3.3. Changes to an order after production has started may result in additional costs and delays.
3.4. Wooden Deco reserves the right to refuse any order due to feasibility or material limitations.
4. Delivery & Installation
4.1. We offer delivery and installation services within [list service areas].
4.2. Delivery times are estimates and may be affected by external factors such as supplier delays.
4.3. Clients must ensure access to the installation site is clear and ready for work to begin.
4.4. Additional charges may apply for complex installations or last-minute rescheduling.
5. Returns & Refunds
5.1. As all products are custom-made, returns and refunds are only available for defective or incorrect items.
5.2. Clients must report defects or issues within 48 hours of delivery.
5.3. Wooden Deco will assess the issue and provide a repair, replacement, or partial refund where applicable.
5.4. Deposits for custom work are non-refundable once production has started.
6. Warranty & Maintenance
6.1. Our products come with a limited warranty covering manufacturing defects for [specify warranty period, e.g., 1 year].
6.2. The warranty does not cover natural wood variations, improper use, or accidental damage.
6.3. Proper care and maintenance guidelines must be followed to ensure product longevity.
7. Intellectual Property
7.1. All website content, including images, designs, and text, is the property of Wooden Deco.
7.2. Unauthorized use, reproduction, or distribution of our content is prohibited.
8. Limitation of Liability
8.1. Wooden Deco is not liable for damages caused by improper installation, misuse, or failure to follow maintenance guidelines.
8.2. We are not responsible for delays caused by third-party suppliers, force majeure events, or other unforeseen circumstances.
9. Privacy Policy
9.1. We collect and store personal information in accordance with our Privacy Policy.
9.2. Your data will not be shared with third parties without consent, except as required by law.
10. Governing Law
10.1. These Terms and Conditions are governed by the laws of Cyprus.
10.2. Any disputes shall be resolved in the courts of the Republic of Cyprus.
11. Changes to Terms
11.1. Wooden Deco reserves the right to update these Terms and Conditions at any time.
11.2. Continued use of our website and services after updates constitutes acceptance of the new terms.
For any questions, please contact us at +35799532143
Limassol,Cyprus